The process of managing procurement relationships, monitoring contract performance, and making changes and corrections as appropriate.
REQUEST FOR PROPOSAL
Prime Contractor – Stadium Construction
Project: International Football Tournament Stadium
Issued By: Ministry of Sports
Project Manager: Alex
RFP Issue Date: 01 February 2026
Proposal Submission Deadline: 30 March 2026
Contract Type: Firm Fixed Price (FFP) with defined escalation provisions
- Project Overview
On 01 September 2025, the country was awarded hosting rights for an international football tournament scheduled for June 2030.
The Ministry of Sports is soliciting proposals from qualified construction firms to deliver a 50,000-seat stadium in accordance with approved architectural and structural design documents.
Target completion date: 31 December 2029.
- Scope Summary
The selected Prime Contractor shall perform:
- Site preparation
- Foundations
- Superstructure
- Roofing & enclosure
- Seating installation
- Turf system installation
- Safety & evacuation systems
- Entry gate installation
- Utilities & services
- Commissioning and certification support
Full scope details are defined in the attached Statement of Work (SOW).
- Contract Type
Firm Fixed Price (FFP).
Key characteristics:
- Defined scope
- Milestone-based payments
- Performance bond required
- Liquidated damages clause
- Strict force majeure definition
Escalation clauses may apply to documented extraordinary global market conditions.
- Proposal Submission Requirements
Proposals must be submitted in two sealed parts:
Part A – Technical Proposal
Must include:
- Construction methodology
- Project execution plan
- Schedule (baseline proposal)
- Risk management approach
- Quality management approach
- Organizational structure
- Key personnel CVs
- Past project references
- Safety record
- Financial capability documentation
Part B – Financial Proposal
Must include:
- Lump-sum total price
- Detailed cost breakdown by WBS
- Cash flow projection
- Contingency assumptions
- Escalation assumptions
- Payment milestone alignment
Financial proposals will not be opened until technical evaluation is complete.
- Technical Requirements
The contractor must demonstrate:
- Experience with stadiums >40,000 seats
- Ability to complete mega-projects within 48 months
- Proven compliance with national safety regulations
- Capability to coordinate with digital integration vendors
- Schedule Requirements
The proposed schedule must:
- Meet 31 December 2029 completion
- Identify critical path
- Include risk mitigation strategies
- Align with integration milestones
Failure to meet mandatory schedule constraints may result in disqualification.
- Quality Requirements
Proposals must include:
- Quality Management Plan
- Inspection and testing procedures
- Subcontractor quality control plan
- Turf certification methodology
- Risk Allocation Requirements
Contractor assumes responsibility for:
- Labor productivity
- Material procurement timing
- Subcontractor performance
Market volatility does not automatically qualify as force majeure.
- Evaluation Criteria
Proposals will be evaluated according to the approved Source Selection Criteria:
Criteria | Weight |
Technical capability | 30% |
Relevant experience | 20% |
Cost proposal | 20% |
Risk management approach | 10% |
Financial stability | 10% |
Schedule feasibility | 10% |
Minimum technical score required: 7.0/10.
- Performance Bond
The selected contractor must provide:
- Performance bond equal to 10% of contract value
- Valid for contract duration
- Payment Terms
Payments will be milestone-based:
- Site preparation completion
- Foundations completion
- Superstructure completion
- Roofing completion
- Turf certification
- Commissioning
- Final acceptance
Retention of 5% until final acceptance.
- Change Management
All scope modifications require:
- Written Change Order
- Cost and schedule impact analysis
- Sponsor approval
Verbal modifications are not binding.
- Dispute Resolution
Disputes shall be handled according to contract terms:
- Project-level negotiation
- Executive mediation
- Arbitration
- Proposal Validity
Proposals must remain valid for 120 days from submission deadline.
- Confidentiality & Compliance
Vendors must confirm:
- No conflict of interest
- Anti-corruption compliance
- Adherence to procurement regulations
- Timeline
Milestone | Date |
RFP Issue | 01 Feb 2026 |
Clarification Period | 01–20 Feb 2026 |
Site Visit | 25 Feb 2026 |
Proposal Submission | 30 Mar 2026 |
Evaluation | April 2026 |
Contract Award | May 2026 |
- Attachments
- Statement of Work
- Design Documents
- Quality Requirements
- Draft Contract Template
- Source Selection Criteria
- Risk Allocation Summary
- Authority
This RFP is issued under authority of the Ministry of Sports and subject to national procurement law.